FIDIC Red Book

Ben Beaumont is a barrister. In addition, he is a chartered surveyor, FRICS, FCIArb and a chartered arbitrator, as which he has more than 30 years of experience. He was a member of the original Marriott committee, which was drawn together to draw up the predecessor to what is now the Arbitration Act 1996. He has adjudicated and arbitrated disputes arising from the FIDIC Suite of Contract Conditions. He sits regularly on DAABs in most jurisdictions. The author has completed the final proof read while commencing a life changing course of Abiraterone under the guidance of Dr Ursula McGovern and the deep friendship of Dr Jonathan Martin.

CHAPTER 1 GENERAL PROVISIONS

CHAPTER 2 THE EMPLOYER

CHAPTER 3 THE ENGINEER

CHAPTER 4 THE CONTRACTOR

CHAPTER 5 SUBCONTRACTING

CHAPTER 6 STAFF AND LABOUR

CHAPTER 7 PLANT, MATERIALS AND WORKMANSHIP

CHAPTER 8 COMMENCEMENT, DELAYS AND SUSPENSION

CHAPTER 9 TESTS ON COMPLETION

CHAPTER 10 EMPLOYER’S TAKING OVER

CHAPTER 11 DEFECTS AFTER TAKING OVER

CHAPTER 12 MEASUREMENT AND VALUATION

CHAPTER 13 VARIATIONS AND ADJUSTMENTS

CHAPTER 14 CONTRACT PRICE AND PAYMENT

CHAPTER 15 TERMINATION BY EMPLOYER

CHAPTER 16 SUSPENSION AND TERMINATION BY CONTRACTOR

CHAPTER 17 CARE OF THE WORKS AND INDEMNITIES

CHAPTER 18 EXCEPTIONAL EVENTS

CHAPTER 19 INSURANCE

CHAPTER 20 EMPLOYER’S AND CONTRACTOR’S CLAIMS

CHAPTER 21 DISPUTES AND ARBITRATION